SetupV1V2
Al-Rahma Housing Contract

Records

Everything that happened, everything that was asked, and every decision behind it.

+10 days estimated impact from open issues

ISS-021Late structural shop drawing approval

Raised by Salim Al Hinai (Contractor) · 10 Feb 2027

Critical pathOpen

Shop drawings for the first floor slab reinforcement (S-204) were returned Status C twice, delaying rebar fixing at grid 7–9 and the subsequent pour.

Category
Design
Responsible
Consultant
Estimated impact
+5 days
Affected activities (3)
  • STR-410FF Slab Reinforcement+5 days
  • STR-430FF Slab Concrete Pour+4 days
  • STR-440FF Slab Curing+3 days
Evidence (4)
  • Shop Drawing S-204 — Status C (1st issue)
  • Shop Drawing S-204 — Status C (2nd issue)
  • Shop Drawing S-204 — Approved
  • RFI-041 — MEP Sleeve Positions

ISS-019Compaction test certificates not provided for north elevation

Raised by Eng. Yousuf Al Rawahi (Consultant) · 16 Jan 2027

Open

Backfill to the north elevation was placed without independent compaction testing. Verification of SUB-170 is suspended until results are provided.

Category
Quality
Responsible
Contractor
Estimated impact
+3 days
Affected activities (1)
  • SUB-170Backfilling & Compaction to Foundations+3 days
Evidence (1)
  • Backfill Compaction — Rejection Notice

ISS-017Waterproofing membrane delivery delayed at port

Raised by Salim Al Hinai (Contractor) · 20 Dec 2026

Mitigated

Imported tanking membrane held in customs clearance for 11 days, delaying foundation waterproofing and the subsequent backfill sequence.

Category
Material
Responsible
Contractor
Estimated impact
+7 days
Affected activities (2)
  • SUB-160Waterproofing & Protection to Foundations+7 days
  • SUB-170Backfilling & Compaction to Foundations+4 days
Evidence (1)
  • Waterproofing Membrane — Customs Clearance

Resolved 05 Jan 2027

ISS-014Municipality permit issued later than tendered assumption

Raised by Salim Al Hinai (Contractor) · 02 Oct 2026

Critical pathClosed

Building permit issued 9 days after the date assumed at tender. Excavation start reprogrammed under Rev 01.

Category
Approval
Responsible
Client
Estimated impact
+9 days
Affected activities (2)
  • PRE-130Building Permit & Municipality Approvals+9 days
  • EXC-100Site Clearance & Levelling+9 days
Evidence (1)
  • Municipality Building Permit

Resolved 09 Oct 2026

ISS-022Honeycombing at column head C4

Raised by Eng. Yousuf Al Rawahi (Consultant) · 20 Feb 2027

Critical pathUnder Review

Surface honeycombing identified at column head C4 during post-pour inspection. Making good required before the affected pour can be certified.

Category
Quality
Responsible
Contractor
Estimated impact
+2 days
Affected activities (1)
  • STR-430FF Slab Concrete Pour+2 days
Evidence (1)
  • Honeycombing at C4 — Method Statement for Making Good

Prototype note — Extension-of-time and variation-order calculation is deliberately not implemented. “Estimated impact” is a human judgement recorded against the activity, not an entitlement. The model carries the links a future EOT engine needs — issue → activities → float → completion — which is what decision D-009 puts in scope.